Thomas Webb and Laureen Webb v. Midwest Storm Company, LLC.

IN THE COURT OF APPEALS OF IOWA

No. 19-0041
Filed April 15, 2020

THOMAS WEBB and LAUREEN WEBB,
Plaintiffs-Appellees,

vs.

MIDWEST STORM COMPANY, LLC.,
Defendant-Appellant.
________________________________________________________________

Appeal from the Iowa District Court for Lee (South) County, Wyatt P.

Peterson, Judge.

Midwest Storm Company, LLC appeals from an adverse jury verdict.

AFFIRMED IN PART, REVERSED IN PART, AND REMANDED.

Victoria D. Noel (until withdrawal) of the Noel Law Firm, Clinton, and

Matthew L. Noel, Dubuque, for appellant.

Curtis Dial of Law Office of Curtis Dial, Keokuk, for appellee.

Considered by Bower, C.J., and May and Greer, JJ.
2

MAY, Judge.

Midwest Storm Company, LLC (Midwest) appeals from an adverse jury

verdict in favor of Thomas Webb and Laureen1 Webb. On appeal, Midwest claims

the district court erred in denying its motion for judgment notwithstanding the

verdict (JNOV). Midwest also alleges the district court erred in not granting its

motion for new trial with respect to its counterclaim. We reverse in part, affirm in

part, and remand.

I. Background Facts and Prior Proceedings

The Webbs hired Midwest to repair damage to their home. Midwest

completed work on the roof and hired a subcontractor to work on the home’s siding.

But Thomas was not satisfied with the quality of the siding work. Thomas told

Midwest not to return or send the subcontractor back. The Webbs’ insurance

company paid Midwest $15,985.88 of the total contract price, which was

somewhere in between $22,000 and $23,000. No one paid the remainder.

The Webbs then brought this action against Midwest. Midwest responded

with a counterclaim against the Webbs. The matter proceeded to jury trial. The

court submitted jury instructions for the Webbs’ claims of breach of contract and

negligence, as well as Midwest’s breach of contract counterclaim.

The jury returned a verdict in favor of the Webbs on their contract and

negligence claims. The jury awarded $7500 in damages for breach of contract

and $1500 “plus lawyer fees and court costs” with respect to the negligence claim.

1 Filings within the record differ as to the spelling of Ms. Webb’s first name. Some
filings refer to Lauren Webb and others to Laureen Webb. We refer to her as
Laureen Webb as that is how her name appears on her appellant brief.
3

As to Midwest’s counterclaim, the jury found the Webbs did not breach the

contract. The district court promptly entered judgment for the Webbs and against

Midwest in the amount of “$9000 plus lawyer fees and court costs.”

On Midwest’s motion, the district court filed a bill of exceptions. It expanded

the record to show that (1) the parties had waived recording of closing argument;

but (2) during closing argument, the Webbs’ attorney stated they were only seeking

$7500 in total damages.

Midwest also moved for new trial and JNOV. The district court conditionally

granted the motion for new trial unless the Webbs filed a remittitur, or written

consent, to reduce their total judgment to $7500. In all other respects, the district

court denied Midwest’s motions for new trial and JNOV.

The Webbs filed a written consent to a reduction of their total judgment to

$7500. Midwest now appeals the court’s denial of its motions for new trial and

JNOV.

II. Scope and Standard of Review

“The purpose of [JNOV] is to allow the district court an opportunity to correct

any error in failing to direct a verdict.” Easton v. Howard, 751 N.W.2d 1, 4 (Iowa

2008). “We . . . review a district court ruling on a motion for [JNOV] for correction

of errors at law.” Thornton v. Am. Interstate Ins. Co., 897 N.W.2d 445, 460 (Iowa

2017) (citation omitted). “Our role is to decide whether there was sufficient

evidence to justify submitting the case to the jury when viewing the evidence in the

light most favorable to the nonmoving party.” Smith v. Iowa State Univ. of Sci. &

Tech., 851 N.W.2d 1, 18 (Iowa 2014) (citation omitted).
4

On appeal, an appellate court’s review is limited to those grounds
raised in the defendant’s motion for a directed verdict. Error must be
raised with some specificity in a directed verdict motion. A motion
for [JNOV] must stand on grounds raised in the directed verdict
motion. On appeal from such judgment, review by an appellate court
is limited to those grounds raised in the directed verdict motion.

Royal Indem. Co. v. Factory Mut. Ins. Co., 786 N.W.2d 839, 844–45 (Iowa 2010)

(citations omitted).

III. Discussion

Midwest argues it was entitled to JNOV as to both the Webbs’ contract claim

and their negligence claim. Midwest also contests the district court’s denial of its

motion for new trial as to its breach-of-contract counter claim.

We begin by addressing the Webbs’ contract claim. Midwest claims that,

as a matter of law, the Webbs could not recover for breach of contract. We agree

for two reasons.

First, the jury was instructed without objection that (1) the Webbs must

prove they have “done what the contract requires”; and (2) if they failed to prove

that proposition, the Webbs would “not [be] entitled to damages.” See Molo Oil

Co. v. River City Ford Truck Sales, Inc., 578 N.W.2d 222, 224 (Iowa 1998)

(providing for a plaintiff to recover for breach of contract the plaintiff must perform

“all the terms and conditions required under the contract”). But it appears

undisputed the Webbs failed to perform their payment obligation under the

contract.2 So the Webbs could not recover under the contract.

2 The Webbs did not file a brief to contest this assertion, Thomas testified he did
not pay the agreed upon amount, and we will not comb the record to build a
responsive argument for a party. See Hyler v. Garner, 548 N.W.2d 864, 876 (Iowa
1996) (determining the court “will not speculate on the arguments [a party] might
have made” or “comb the record for facts to support such arguments”).
5

Moreover, the jury was instructed without objection that a party’s

performance “is excused if the other party prevents it or makes it impossible.” And

it appears undisputed the Webbs prevented Midwest from addressing the Webbs’

concerns with the siding work.3 This excused Midwest’s performance and

foreclosed recovery by the Webbs. See Sheer Constr., Inc. v. W. Hodgman &

Sons, Inc., 326 N.W.2d 328, 332 (Iowa 1982) (noting construction contracts have

“an implied term that the person for whom the work is contracted to be done will

not obstruct, hinder or delay the contractor, but, on the contrary, will in all ways

facilitate the performance of the work to be done by [the contractor]” (citation

omitted)). So, as to the Webbs’ contract claim, we conclude Midwest was entitled

to JNOV.

We next address Midwest’s challenge to the negligence award. As a

practical matter, we recognize our review of this issue may have little effect. The

Webbs consented to limiting their recovery to $7500. This eliminated the amounts

awarded for their negligence claim.

Nonetheless, as Midwest argues, the Webbs did not plead or prove a viable

negligence theory. The Webbs alleged Midwest “did not complete” home repairs

that Midwest “had agreed to complete” under “a verbal contract.” Moreover, the

Webbs alleged, the work Midwest completed under the contract “was not done

properly.” As for damages, the Webbs alleged they had to “pay other contractors”

to “finish” the work Midwest “had agreed to complete,” and to “repair the work”

3Again, we note the Webbs did not file an appellate brief contesting this claim, and
we will not scour the record to construct a responsive argument on their behalf.
See Hyler, 548 N.W.2d at 876.
6

Midwest “performed incorrectly.” These are contract claims, not negligence

claims. See Annett Holdings, Inc. v. Kum & Go, L.C., 801 N.W.2d 499, 503 (Iowa

2011) (“When two parties have a contractual relationship, the economic loss rule

prevents one party from bringing a negligence action against the other over the

first party’s defeated expectations—a subject matter the parties can be presumed

to have allocated between themselves in their contract.”); see generally Jeffrey L.

Goodman et. al., A Guide to Understanding the Economic Loss Doctrine, 67 Drake

L. Rev. 1 (2019). So Midwest was entitled to JNOV as to the Webbs’ negligence

claim.

Finally, we address Midwest’s claim that it is entitled to a new trial with

respect to its counterclaim asserting a breach-of-contract claim against the Webbs.

Midwest’s motion for new trial asserted, “On the count submitted by the [d]efendant

the jury affixed an amount too small.” On appeal, though, Midwest raises

arguments about liability, not damages. We conclude Midwest’s complaint to the

district court concerning damages did not preserve its appellate claim regarding

liability.4 See Grefe & Sidney v. Watters, 525 N.W.2d 821, 825 (Iowa 1994)

(concluding a party may not make a new argument on appeal).

IV. Conclusion

We affirm the district court’s ruling on Midwest’s motion for new trial with

respect to Midwest’s counterclaim. We reverse the district court’s ruling on

4 We may raise the issue of error preservation sua sponte. See Top of Iowa Co-
op. v. Sime Farms, Inc., 608 N.W.2d 454, 470 (Iowa 2000) (“In view of the range
of interests protected by our error preservation rules, this court will consider on
appeal whether error was preserved despite the opposing party’s omission in not
raising this issue at trial or on appeal.”).
7

Midwest’s motion for JNOV and remand for entry of judgment in favor of Midwest

as to the Webbs’ breach-of-contract claim and negligence claim.

AFFIRMED IN PART, REVERSED IN PART, AND REMANDED.