City of Forth Smith v. B&A Electric, Inc.

Cite as 2023 Ark. App. 24
ARKANSAS COURT OF APPEALS
DIVISION I
No. CV-21-569

CITY OF FORT SMITH Opinion Delivered January 25, 2023
APPELLANT
APPEAL FROM THE SEBASTIAN
COUNTY CIRCUIT COURT,
V. FORT SMITH DISTRICT
[NO. 66FCV-17-285]
B&A ELECTRIC, INC.; MEGEHEE
FENCE CONTRACTING, LLC; GRIMES HONORABLE STEPHEN TABOR,
DOZER SERVICE, INC.; JAMES JUDGE
GRIFFITH; AND RIVER VALLEY
SPORTS COMPLEX, INC.
APPELLEES REVERSED AND DISMISSED

WAYMOND M. BROWN, Judge

The City of Fort Smith (the City) appeals the Sebastian County Circuit Court’s entry

of judgment against it following a jury verdict on breach-of-contract claims brought by

appellees B&A Electric, Inc.; Megehee Fence Contracting, LLC; Grimes Dozer Service, Inc.;

and James Griffith (the contractors), hired by third-party defendant River Valley Sports

Complex, Inc. (RVSC). The City contends that the evidence was insufficient to support the

judgment in favor of the contractors. We agree. Therefore, we reverse and dismiss this

action.1

1
This is the third time this case has been before us—we dismissed it twice for lack of a
final order. See City of Fort Smith v. B&A Electric, Inc., 2019 Ark. App. 575; City of Fort Smith
v. B&A Electric, Inc., 2021 Ark. App. 334.
The City and RVSC entered into a written contract in March 2014 for the

construction of a sports complex on city-owned land after RVSC principals Jake Files and

Lee Webb presented the project to the city board. The City agreed to contribute up to $1.6

million in amounts payable when construction reached specific milestones. RVSC solicited

donations to cover the remaining costs of the project. The contract required RVSC to

complete the project by June 10, 2015, but stated that after construction was complete, the

City would lease the complex back to RVSC for ten years.

RVSC began work on the project in 2014, and it hired the four appellees as

contractors to provide materials and services. By the scheduled completion date, however,

RVSC had not substantially completed the work. Work continued into 2016 as a result of

two negotiated extensions granted by the City. The City paid RVSC over $1.08 million, but

in early 2017, RVSC permanently ceased working on the project after having failed to meet

the deadline extensions. When RVSC abandoned the project, it owed all four contractors

payment for work and materials they had already provided. The contractors sought payment

from RVSC, but RVSC did not have sufficient funds to pay. The contractors then sued the

City for breach of contract and unjust enrichment. The City filed a third-party complaint

against RVSC for breach of contract and contractual indemnity.

The case went to trial before a jury in September 2018. Terry Bailey, the bookkeeper

and corporate secretary for Grimes Dozer Service, testified that she compiled and submitted

invoices to RVSC between 2014 and 2016. She stated that Grimes had been paid for all the

work performed except $12,977.50 for which it was seeking judgment against the City.

2
On cross-examination, Bailey stated that all the invoices were directed to Webb

because its agreement was with RVSC. She said that it billed RVSC and received payments

from RVSC. She denied ever receiving checks from the City. She testified that Grimes

billed the City on advice from its attorney to do so after work on the project had stopped.

She said that Grimes was not paid after July 2016 “because RVSC did not receive another

draw from the City because RVSC had not completed the next phase, and there was no

money to pay us.”

On redirect, Bailey stated that she knew the land was owned by the City and that in

her mind, “the City would direct the money to RVSC and then to us.”

Brian Buzbee, part owner of B&A Electric, testified that he submitted budget

numbers to the City to provide lights, poles, and concrete bases for the softball fields in 2014

and that the City subsequently passed a resolution with that bid exhibited. He stated that it

received $40,000 as final payment, but it was expecting $100,000. He said that RVSC told

B&A Electric that “we weren’t getting any more money from the City.” He testified that he

met with his supplier, Upchurch Electric, and the city auditor, Tracey Shockley, and looked

at the site and what had been done up to that point. He said that he subsequently pulled

out all the panel “guts” and wiring it had installed to protect it from vandalism. He stated

that it had completed all the work for which invoices were submitted to RVSC or the City.

Buzbee testified that he attended a city board of directors meeting in March 2017 to inquire

about why RVSC was not required to submit a performance bond and was told by Michael

3
Lorenz that “the City viewed it as a collaboration between the City and RVSC.” He stated

that it is still owed $151,880 for which it was seeking judgment against the City.

On cross-examination, Buzbee testified that all the invoices were directed to Webb,

never the City. He further testified, “We never received any document from the City

indicating we had won a bid. We have no agreement with the City that it will be responsible

for the goods and services we delivered to the project, but the City has possession of the

boxes and light poles.”

On redirect, Buzbee stated that the City’s resolution referenced $458,000, the exact

amount of B&A Electric’s bid. He contended that the City had not offered to pay B&A

anything on the remaining balance.

James Griffith testified that he was hired by RVSC to do some woodwork for the

project. He stated that he kept his costs at a certain level as requested by Webb. He said

that he put up walls, set roof trusses, put roof decking in, and wrapped the buildings. He

stated that he completed everything he was contracted to do and was still waiting to be paid

the $20,337 for which he was seeking judgment against the City. He said that he contacted

Webb for payment and attempted to contact the City three times, but the City never called

back. He stated that although Webb was running the project, “we all believed the City was

paying payments based on completion milestones.”

On cross-examination, Griffith stated that he gave a verbal bid to Webb and that he

had no written agreement with the City to pay for his services. He stated that Webb

4
approved everything he did. He said that he realized he would not be paid when the City

shut down the project. He further testified,

I put the responsibility on the City because it halted the project and stopped the
funding. I decided to sue the City because the City controlled the money. I have no
written or verbal agreement with the City. No representative of the City told me the
City would cover my expenses for the project.

On redirect, Griffith said that it was common for him not to receive verbal or written

agreements for payment. He stated that ordinarily, he could file a lien for nonpayment, but

that is not an option against the City.

Shawn Megehee2 testified that he is the owner of Megehee Fence Contracting, LLC.

He said that he was asked by Webb to perform work for the project and that he was aware

that the project was on land owned by the City. He said that his company installed all the

fencing per the agreement. He also stated that he left materials in Webb’s yard and

warehouse that subsequently disappeared. He testified that he billed RVSC for $45,482.08

but only received payment in the amount of $30,500. He was seeking judgment against the

City for the remaining amount owed.

After the close of the contractors’ case, the City moved for directed verdict on both

claims. The court denied the motion.

Jeff Dingham, deputy city administrator for the City of Fort Smith, testified that the

City was initially contacted by Files and Webb in 2011 about a sports complex. He said that

2
The transcript reflects the last name as McGehee, but for purposes of this opinion,
we will refer to it as Megehee.

5
at that time, the City did not own the land in question. He stated that the agreement was

not considered by the board of directors until March 2014. He testified that the City was to

contribute up to $1.6 million, to be paid incrementally upon the accomplishment of

construction milestones as set out in the agreement and that the estimated total cost for the

construction was about $6 million but that RVSC was to seek donations of time, materials,

and labor to get the project completed. He admitted that the project was not bonded, but

he stated that Files and Webb offered financial assurances in lieu of a bond. He said that

RVSC made personal financial guarantees and RVSC assured the City that it would be

successful in seeking donations of money, time, and materials to complete the project. He

stated that the City was not actively involved in the management of the project and that Files

and Webb handled all arrangements for providing contractors, supplies, and vendors. He

said that RVSC never requested the City to compensate any suppliers, vendors, or

construction services. He testified that the City agreed to two extensions when RVSC did

not meet the original completion date of July 1, 2015, and that at the end of the second

extension in July 2016, RVSC asked for more time because the project was still not complete.

However, he stated that they never entered into specific discussions about more time. He

testified that RVSC submitted a timeline showing a completion date of November 15, 2016,

which it did not meet; and it submitted another proposed schedule showing a completion

date of December 20, 2016, which it also failed to meet. Dingham stated that by December

2016, a lot of the responsibility for the project had shifted to Carl Geffken, the city

administrator.

6
On cross-examination, Dingham stated that he knew RVSC was a non-profit

organization that was unfunded and had no assets, making it virtually impossible for it to

secure a performance bond. He acknowledged that the City entered into a construction

contract with RVSC in spite of this. He stated that the City acquired ownership of the

property for the project in 2012. He denied that the City sent any engineers or architects to

investigate whether this was a feasible project to complete until everything “went bad.” At

that time, he said that the City developed an accounting of what was on the property as

compared to what the City had paid toward the project. He stated that the value of the

goods and services was commensurate with the amount the City had paid out; that RVSC

was selling the City a completed complex of structure, fencing, and ball fields to be owned

by the City; and that the agreement set out the specifications and standards for the complex

for which RVSC was required to adhere. He testified that $1.6 million was earmarked for

the project and that there was still money remaining in the budget. He further testified,

The City was observing and monitoring the project. Parks and Recreation
Department employees were out there frequently. The City knew that contractors
had been retained by RVSC and doing work on the project. The City did not have a
specific relationship with the other contractors. This project was significantly
underfunded. The City’s position is that it has a contract with RVSC, not with the
other contractors. No performance bond or surety was obtained in July 2015 when
the first extension was agreed [to]. The City did not do anything to secure payment
to the contractors who worked on the project, or to get a personal surety bond from
Webb or Files, or to warn the contractors they might not get paid. The City had no
relationship with any of the contractors and it did not contact any of them.

The City did not distribute any money without RVSC having met the construction
milestones. At some point the City requested to look at RVSC’s checks written and
bank statements, and to see exactly what funds had been paid out by RVSC. City
employees were on the property periodically, every day in some weeks, seeing what

7
was going on. The agreement was a contract between the City and RVSC for the
construction of this complex on City-owned property. RVSC had no other sources
of income to my knowledge. The City paid RVSC $1.08 million. The City passed
resolutions allowing all this to happen. The Financial Assurances document in
Exhibit 1 lists items that needed to happen on the property for the project to occur
and where different components would come from. Assurances were provided to the
satisfaction of the Board of Directors, but there were no assurances in the
conventional sense.

On cross-examination by RVSC, Dingham stated that a report prepared by Morrison-

Shipley Engineers showed that the value of work the City received was $1.18 million,

$100,000 more than what the City had paid out. He stated that the agreement was

terminated because of delays and that he believed city employees picked up materials and

some donated air conditioners from Webb’s place. He testified that the City requested

RVSC’s bank statements, check ledgers, and documents, which were provided as requested.

On redirect, Dingham stated that the City estimated that an additional $3.5 million

would be required to complete the project. He said that as deputy city administrator, he had

no confidence that RVSC would be able to deliver what it promised to deliver in the

agreement.

On recross, Dingham stated that the financial-assurances document was never

thought of as a bond but as a way to make the project happen. He admitted that the lack of

a bond had put the contractors and other people in a terrible position.

Carl Geffken testified that he was the city administrator for the City of Fort Smith

and had served in that capacity since May 16, 2016. He stated that the City wanted the

project to succeed; however, after RVSC failed to meet the extended deadlines for

8
completion, he recommended that the City explore termination of the agreement. He stated

that Files approached him about getting General Improvement Fund (GIF) money for sewer

and water improvements on the property and that he was able to secure $45,070 in GIF

money. He testified that he paid $26,945 of that money to DiAnna Gonzales for work on

the project. He stated that the board of directors asked RVSC to submit a revised estimated

date of completion by January 31, 2017, and that a completion date of September 2017 was

subsequently given. He stated that Shockley requested bank statements, checks, and other

information from RVSC. He testified that on February 1, he issued a cease-and-desist order

to ensure nothing went into or came out of the sports complex. He stated that on February

3, Files called him to talk about withdrawing from the contract, but he had already told Files

that the contract would probably be terminated. On February 7, Geffken stated that the

board of directors approved a resolution to terminate the contract with RVSC. He stated

that RVSC did not offer to cure any default in the contract and that some of the contractors

called the City requesting payment. He testified that in his view, this was a public-private

partnership like another partnership the City was involved in at the time. He stated that

there is $520,000 left in the City’s budget for the project. However, he said that engineers

estimate that it will cost a total of $5 million to complete the project, far more than what

remains in the budget.

On cross-examination, Geffken testified that the City decided it was not going to pay

anyone else based on its relationship with RVSC. He stated that the City’s money was just

the “seed money to help fill the gaps.” He said that the sports complex was a collaboration

9
in which the City contributed $1.6 million and RVSC was to achieve donations of $3 million

through contributions or direct funding, that RVSC was not a project manager, and that the

City did not hire the contractors. He testified that it was in the scope of the business plan

for RVSC to have money to hire contractors and that RVSC was on the hook to make the

payments. He indicated that surety bonds are never a requirement, but it is the proper thing

to do. However, he stated that the board of directors decided to go forward with what was

unconventional. He said that he did not dispute that the contractors performed the work

for which they sought payment but that the City had no intention of paying them. He said

that the City found out that RVSC had no funds, but that was not the original plan as he

understood it. He admitted that there is enough money left in the City’s budget to pay the

contractors.

On cross-examination by RVSC, Geffken stated that he recommended to the board

of directors in December 2016 that the contract with RVSC be terminated. He said that

RVSC’s notice of withdrawal came on February 3.

On recross, Geffken stated that he would like for RVSC to honor the contract it had

with the contractors it hired. He denied that the contractors provided goods and services to

the City but contended they did so for RVSC. He admitted that the City was going to own

the complex.

Tracey Shockley testified that she is the internal auditor for the City of Fort Smith.

She said that she first knew of the project in January 2017 after a board of directors study

session when she was asked to look into it. She stated that she met with Buzbee and agreed

10
that he could remove his materials from the job site. She said that she also spoke with

Megehee about materials he had left at the job site but learned from Webb that those

materials had already been paid for. She said that Megehee left, and the City made

arrangements with Webb to secure all the items.

Lee Webb testified that he and Files were the organizers of RVSC. He stated that the

purpose of RVSC was to create a softball complex to host tournaments. He said that Fort

Chaffee donated 62.5 acres of property to the City and that there were various other

donations made to the project. He stated that when certain thresholds were met, the City

would send an inspector out, a check would be issued for the work, and he would then pay

the contractors. He testified that it was communicated to the City that RVSC did not have

any assets. He said that in January 2017, the City asked for a new completion deadline. He

stated that RVSC provided bank statements and a breakdown of what the contractors were

owed, as requested by the City. He said that he attended the study session in January 2017,

and there was no mention of terminating the agreement at that time. He stated that he

received a letter on February 1 requesting RVSC to cease and desist from doing work on the

project; that RVSC subsequently sent a withdrawal letter to the City on February 3; and that

RVSC received a letter of termination on March 17. He testified that after termination of

the contract, he cooperated with the City to pick up materials, including air conditioning

units, backstop poles, and fencing. He opined that the materials picked up by the City were

already paid for.

11
On cross-examination by the City, Webb stated that RVSC had not met any of the

deadlines as set out in the agreement and extensions and that he hired all the contractors

and they answered to him. He said that the contractors billed RVSC and that he paid them.

He stated that he did not send the contractors to the City to be paid because RVSC was

responsible for paying them once the draw money came in. He testified that RVSC received

payments from the City for the contract thresholds that were completed.

On cross-examination by the contractors, Webb stated that the agreement with the

City was drafted by the City’s attorneys. He said that the agreement set forth what RVSC

could and could not do in developing the property as well as the design, the standards of

construction, the time for completion, and the payment schedule. The agreement also

waived a performance bond. He testified that the only money in RVSC’s account came from

the City, with the exception of a refund for pallets and that the contributions from third

parties were materials or materials at cost. Webb testified that the City monitored the work

being performed, controlled all the money, inspected the work, and subsequently stopped

the contract. He stated that the contractors performed all the work they invoiced and are

owed all the money they are claiming. He said that the City gave RVSC authority to hire

the contractors and that RVSC was going to benefit by being allowed to lease the property

for ten years after completion. He said that RVSC received no payment or management

fees. He opined that this was a collaboration between two parties.

At the close of all evidence, the City renewed its motion, which the court again

denied. The jury returned verdicts in favor of the contractors for the full amount of their

12
requested damages on both their breach-of-contract claims and their unjust-enrichment

claims.3 The jury found in favor of RVSC on the City’s third-party claims. The parties

agreed that the jury’s verdicts granting relief to the contractors on their breach-of-contract

and unjust-enrichment claims were incompatible, and with the consent of the parties, the

court entered judgment against the City on only the contractors’ breach-of-contract claims.

The City now appeals.

In reviewing a jury’s verdict, our appellate courts determine whether it is supported

by substantial evidence.4 Substantial evidence is that which goes beyond suspicion or

conjecture and is sufficient to compel a conclusion one way or the other. 5 In determining

whether there is substantial evidence, we view the evidence and all reasonable inferences

arising therefrom in the light most favorable to the party on whose behalf judgment was

entered.6 It is not an appellate court’s province to try issues of fact; we simply examine the

record to determine if there is substantial evidence to support the jury verdict. 7 The weight

and value of testimony is a matter within the exclusive province of the jury.8

3
B&A Electric was awarded $151,880; Megehee Fence Contracting was awarded
$14,926.88; Grimes Dozer Service was awarded $12,977.50; and James Griffith was awarded
$20,337.50.

4
Hunter v. Keck, 2020 Ark. App. 233, 600 S.W.3d 109.

5
Id.
6
Id.

7
Id.

8
Id.

13
The City contends that the evidence was insufficient to support the jury’s verdict in

favor of the contractors for their breach-of-contract claims. In order to prove a breach-of-

contract claim, one must prove the existence of an agreement, breach of the agreement, and

resulting damages.9 Here, the City contends— and the contractors concede— that there was

no direct contract between the parties. At all relevant times, the City had an agreement with

RVSC, and RVSC had agreements with the contractors.

The contractors argue that RVSC was an agent for the City with direct authority to

act and contract on the City’s behalf. A party asserting the existence of an agency

relationship has the burden of proving that an agency relationship exists.10 The two essential

elements of an agency relationship are (1) that an agent has the authority to act for the

principal and (2) that the agent act on the principal’s behalf and be subject to the principal’s

control.11 The City contends that there is no evidence of an agency relationship between it

and RVSC; however, the contractors list a number of things that they contend support the

existence of such a relationship: (1) the City approved invoices before they were paid; (2)

the City represented to B&A Electric that the City viewed the project as a collaboration

between the City and RVSC; (3) the City took possession of job materials that were provided

by the contractors but for which RVSC did not make payment; (4) the City retained all

9
Stone v. Read, 2022 Ark. App. 349.

10
Hardin v. Bishop, 2013 Ark. App. 395, 430 S.W.3d 49.

11
Id.

14
materials and improvements, regardless of whether the City had paid for them; (5) the City

monitored the project regularly, including daily monitoring, on a frequent basis; (6) the City

controlled distribution of money; (7) the City monitored RVSC’s checks and bank

statements; (8) a city engineer would look at the work and approve it; (9) contractors

submitted budgeting numbers directly to the City; (10) contractors and the City worked

together to incorporate contractor figures into the City’s resolution and agreement; (11) the

City chose to waive any performance bond and rely directly on the budget numbers provided

by the contractors; and (12) a city employee and a city auditor met directly with contractors

to review the work of the contractors. Despite the items listed by appellees to prove an

alleged agency relationship between the City and RVSC, there was no evidence or testimony

by any of the parties that RVSC was indeed the City’s agent. Although the City gave RVSC

the authority to hire the contractors, it had little involvement concerning which contractors

RVSC hired or how the contractors performed their jobs except for making inspections

when thresholds were met. The City denied the existence of an agency relationship, and

RVSC did not offer any testimony to support a finding of such a relationship. As a matter

of fact, Webb testified that RVSC hired the contractors, that the contractors answered to

RVSC, and that RVSC was responsible for paying them. Even if the contractors believed

they had a contractual relationship with the City via their verbal contracts with RVSC, belief

alone is not enough to support a finding that RVSC was an agent for the City.

The City also maintains that there can be no apparent or implied agency authority

imputed against it. The City is correct that an actual agency relationship has to exist, even

15
if it appeared that RVSC had the authority to bind the City. We have already determined

that there was no actual agency relationship between the City and RVSC; therefore, because

the City is a sovereign, there can be no apparent or implied agency relationship between the

parties.12 Accordingly, the jury’s verdict in favor of the contractors’ breach-of-contract claims

is not supported by substantial evidence, and we reverse and dismiss.

Reversed and dismissed.

ABRAMSON and GLADWIN, JJ., agree.

Gilker & Jones, P.A., by: Michael R. Jones, for appellant.

Walters, Allison, Parker & Estell, by: Derick Allison, for appellees.

12
See City of Bryant v. Collins, 2011 Ark. App. 713, 386 S.W.3d 699.

16